August 29, 2019 Legals

NOTICE OF CHANGE OF NAME
TO WHOM IT MAY CONCERN: 19CN-DR00042
YOU ARE HEREBY NOTIFIED that a Judgment was entered on the 16th day of July, 2019 in the Circuit Court of Clinton County, State of Missouri, the name of Penelope Aileen Giltner to be changed to Penelope Aileen Warner.
ELLIS
DOCKRAY
CIRCUIT CLERK
   8/29, 9/5, 9/12c

SIDEWALK REPLACEMENT BID REQUEST
The City of Plattsburg is seeking bids to replace sidewalks. The scope of work includes the removal and replacement of approximately 2500 square feet of concrete sidewalk at City Hall.   Sealed bids will be accepted at City Hall, 114 Maple St. until September 30, 2019.  For more information or a bid packet, contact Greg Harris at 816-539-2148 or gharris@plattsburg-mo.gov.  
       8/22, 29, 9/5c

NOTICE OF CHANGE OF NAME
TO WHOM IT MAY CONCERN: 19CN-DR00028
YOU ARE HEREBY NOTIFIED that by a Judgment entered on the 11th day of June, 2019 in the Circuit Court of Clinton County, State of Missouri, the name of Alexia Jade Maxwell was changed to Alexia Jade Filley.
ELLIS DOCKRAY CIRCUIT CLERK
BY: CONNIE THARP, SENIOR CLERK               
                                                                            8/22, 29, 9/5c

NOTICE OF CHANGE OF NAME
TO WHOM IT MAY CONCERN: 19CN-DR00072
YOU ARE HEREBY NOTIFIED that a Judgment was entered on the 11th day of June, 2019 in the Circuit Court of Clinton County, State of Missouri, the name of Christina Monique Herring be changed to Christina Monique Filley.
ELLIS DOCKRAY CIRCUIT CLERK
BY: CONNIE THARP, SENIOR CLERK               
                                                                            8/22, 29, 9/5c

TRUSTEE’S SALE
IN RE: Stephen C. Scroggins and Valerie Scroggins husband and wife Trustee’s Sale:

    For default in payment of debt and performance of obligation secured by Deed of Trust executed by Stephen C. Scroggins and Valerie Scroggins husband and wife dated October 21, 2002 and recorded in the Office of the Recorder of Deeds of Clinton County, Missouri  as Document No.: 2002-5287 re-recorded June 26, 2015 as Document No.: 2015-1745 the undersigned Successor Trustee, at the request of the legal holder of said Note will on Monday, September 16, 2019 between the hours of 9:00 a.m. and 5:00 p.m., (at the specific time of 12:50 PM), at the West Front Door of the Court House, City of Plattsburg, County of Clinton, State of Missouri, sell at public vendue to the highest bidder for cash the following described real estate, described in said Deed of Trust, and situated in Clinton County, State of Missouri, to wit:
THE SOUTH SEVENTY-FIVE (75) FEET OF LOTS TWENTY-FIVE (25) AND TWENTY-SEVEN (27), FORD’S SECOND ADDITION TO THE CITY OF CAMERON, CLINTON COUNTY, MISSOURI. EXCEPT THE NORTH FIVE (5) FEET OF SOUTH SEVENTY-FIVE (75) FEET OF LOTS TWENTY-FIVE (25) AND TWENTY-SEVEN (27), ON PRAIRIE STREET IN FORD’S SECOND ADDITION TO THE CITY OF CAMERON, CLINTON COUNTY, MISSOURI.

to satisfy said debt and cost.
MILLSAP & SINGER, P.C.,
Successor Trustee
612 Spirit Drive
St. Louis, MO 63005
(636) 537-0110
File No: 190341.091619.398606 FC

Notice
    Pursuant to the Fair Debt Collection Practices Act, 15 U.S.C. §1692c(b), no information concerning the collection of this debt may be given without the prior consent of the consumer given directly to the debt collector or the express permission of a court of competent jurisdiction.  The debt collector is attempting to collect a debt and any information obtained will be used for that purpose.

PUBLISH ON: August 22, 2019 08/29/2019, 09/05/2019, 09/12/2019                                               
                                                                            8/22, 29, 9/5, 12c

IN THE 43RD JUDICIAL CIRCUIT COURT, CLINTON COUNTY, MISSOURI   Probate Division: Case Number: 19CN-PR00053
In the Estate of HOLLIS T. BRAZELTON, Deceased.
Notice of Letters  Testamentary Granted
(Independent Administration)
To All Persons Interested in the Estate of HOLLIS T BRAZELTON, Decedent:
    On AUGUST 9, 2019, the last will of the decedent having been admitted to probate, the following individuals were appointed co-personal representatives of the estate of HOLLIS T. BRAZELTON, decedent, by the Probate Division of the Circuit Court of Clinton County, Missouri. The co-personal representatives may administer the estate independently without adjudication, order, or direction of the Probate Division of the Circuit Court, unless a petition for supervised administration is made to and granted by the court. The names and business addresses of the copersonal representatives are: JAN MAYES, 3055 LITTLE PLATTE ROAD, SMITHVILLE, MO 64089; LYNN CARLSON, 813 CHERRY LANE, SMITHVILLE, MO 64089; The co-personal representatives’ attorney’s name, business address and phone number is): JENNIFER MYERS SNIDER , P O BOX 1517, 2300 HIGGINS ROAD, PLATTE CITY, MO 64079.
    All creditors of said decedent are notified to file claims in court within six months from the date of the first publication of this notice or if a copy of this notice was mailed to, or served upon, such creditor by the co-personal representatives, then within two months from the date it was mailed or served, whichever is later, or be forever barred to the fullest extent permissible by law. Such six-month period and such two-month period do not extend the limitation period that would bar claims one year after the decedent’s death, as provided in Section 473.444, RSMo, or any other applicable limitation periods. Nothing in Section 473.033, RSMo, shall be construed to bar any action against a decedent’s liability insurance carrier through a defendant ad litem pursuant to Section 537.021, RSMo.
    Date of the Decedent’s Death: 30-MAY-2019
    Date of First Publication: AUGUST 15, 2019
ELLIS DOCKRAY, CIRCUIT CLERK
By: Nancy Kelly, Probate Clerk
    Receipt of this notice by mail should not be construed by the recipient to indicate that the recipient necessarily has a
beneficial interest in the estate. The nature and extent of any person’s interest, if any, can be determined from the files
and records of this estate in the Probate Division  of  the   above   referenced  Circuit Court.                      8/15, 22, 29, 9/5c

NOTICE TO BIDDERS
NOTICE OF TAKING BIDS FOR THE CONSTRUCTION OF WASTEWATER COLLECTION SYSTEM IMPROVEMENTS FOR THE CITY OF LATHROP, MISSOURI
    Sealed proposals will be received by the City Clerk of the City of Lathrop, Missouri, at City Hall, 707 Oak Street, Lathrop, Missouri 64465, before 3:00 P.M. on the 3rd day of October, 2019, for the construction of the Wastewater Treatment Facilities Improvements as described in the plans and specifications therefore, now on file in the office of the City Clerk. Proposals will be opened and the amount of the bids announced by a City Representative at the time and date specified above. There will be a nonmandatory pre-bid meeting held at Brazelton Community Center, 707 Oak Street, Lathrop, Missouri 64465 on the 12th day of September, 2019 at 4:00 P.M.
    The location of the work to be done and the kinds and sizes of materials proposed to be used are as follows:
WASTEWATER COLLECTION SYSTEM IMPROVEMENTS
Construct improvements including all labor, materials and equipment necessary to construct approximately 31,000 linear feet of 8-inch cured in place pipe lining, 8,200 feet of l0-inch cured in place pipe lining 1,200 feet of 12-inch cured in place pipe lining, open cut spot repairs, manhole rehabilitation by cementitious liner, cleaning, testing, televising, bypass pumping, sewer service connections, traffic control and miscellaneous associated work, including cleanup. Construct improvements including all labor, material and equipment necessary to construct approximately 2,400 linear feet of 8-inch sewer line, 4,400 linear feet of 10-inch sewer line, 24 manholes, a lift station, 2,000 linear feet of 6-inch force main directional bored, traffic control and miscellaneous associated work, including cleanup.
    All work and materials are to be in accordance with the proposed plans, specifications, form of contract and estimate of cost now on file in the office of the City Clerk of Lathrop, Missouri, and by this reference made a part thereof as though fully set out and incorporated herein.
    All proposals and bids in connection therewith shall be submitted to the City Clerk of said City on or before the time herein set for receiving bids. All proposals shall be made on official bidding blanks furnished by the City, and any alterations in the official form of proposal will entitle the Board of Alderman, at its option, to reject the proposal involved from consideration. Each proposal shall be sealed and plainly identified.
    Each proposal shall be made out on a blank form furnished by the municipality and must be accompanied by bid security in a sealed envelope by either (1) a certified or cashier’s check drawn on a solvent Missouri chartered bank or a bank chartered under the laws of the United States, or a certified share draft drawn on a credit union in Missouri or chartered under the laws of the United States, in an amount equal to 5% of the bid, or (2) a bid bond executed by a corporation authorized to contract as a surety in the State of Missouri, in the penal sum of 5% of the bid.
    The bid security should be made payable to THE CITY OF LATHROP, MISSOURI. The bid security must not contain any conditions either in the body or as an endorsement thereon. The bid security shall be forfeited to the City as liquidated damages in the event the successful bidder fails or refuses to enter into a contract within 10 days after the award of contract and post bond satisfactory to the City insuring the faithful fulfillment of the contract and the maintenance of said work, if required, pursuant to the provisions of this notice and other contract documents. Bidders shall use the bid bond form included in the specifications.
    This project is financed through the Missouri State Revolving Fund (SRF), established by the sale of Missouri Water Pollution Control bonds and Federal Capitalization Grants to Missouri. SRF projects require compliance on several requirements that are explained in the contract documents including:
    • Prevailing wage rates
    • DBE (MBE/WBE)
    • EEO
    • Domestic Products Procurement Law Certification
    • American Iron and Steel Products
    The City of Lathrop is an Equal Opportunity Employer and invites the submission of bids from Women and Minority Business Enterprises.
Nondiscrimination in Employment
    Bidders will be required to comply with the President’s Executive Order No. 11246. Requirements for bidders and contractors under this order are explained in the specifications.
    Bidders will be required to take affirmative steps to involve Disadvantaged Business Enterprise (DBE) in the work under the contract. Bidders shall complete the applicable certification attached to the proposal. The certification shall include a listing of DBEs, the work and estimated dollar amount to be performed by each such enterprise, and the percentage of the total bid to be used for disadvantaged business enterprise(s). The bidder commits itself to the goals for DBE participation contained herein and all other requirements, terms and conditions of these bid conditions when it submits a properly signed bid.
    Any bidder or equipment supplier whose firm or affiliate is listed in the GSA publication “List of Parties Excluded from Federal Procurement and Nonprocurement Programs” will be prohibited from the bidding process. Anyone submitting a bid who is listed in this publication will be determined to be a nonresponsive bidder in accordance with 40 CFR Part31.
    A Contractor’s Suspension/Debarment Certification will be contained in the specifications; however, this certification should not preclude any interested party from ascertaining whether the certifying person is actually on the “List of Parties Excluded from Federal Procurement and Nonprocurement Programs”.
    Bidders will be required to follow prevailing wage rate requirements. The prevailing wage rates table will be contained in the specifications.
    In accordance with Chapter 71.140, Missouri Revised Statues 1986, preference will be given to products and provisions grown and coal produced within the State of Missouri, and to Missouri domestic labor, to the extent lawfully required under Missouri Statutes; provided that the award of contract will be made to the lowest responsible bidder submitting the lowest responsive bid, which shall be determined without regard to state or local law whereby preference is given on factors other than the amount of the bid.
    The City reserves the right to reject any and all bids for a sound, documented reason, to waive informalities and technicalities and to enter into such contract as it shall deem for the best interest of the City.
    The City reserves the right to defer acceptance of any proposal for a period not to exceed sixty (60) calendar days from the date of hearing.
    On the basis of the bids received, the Board of Alderman may propose award for the contract. Final award will not be made until the proposed award is approved by the Department of Natural Resources of the State of Missouri. It is anticipated that such approval will be made within thirty (30) days after application for approval of the proposed award. No claims for compensable delay shall arise as the result of delay in the approval of award.
    The successful bidder will be required to furnish separate performance and payment bonds each in an amount equal to one hundred percent (100%) of the contract price, are required by 10 CSR 20-4.040(18) on construction contracts of $100,000 or more. Where bonds are required, they must be obtained from companies holding certificates of authority as acceptable sureties (31 CFR Part 223).
    The work under the contract shall commence within ten (10) days after date set forth in written Notice to Proceed (NTP). The Wastewater Collection System Improvements shall be in operation and conveying wastewater by 12 months from NTP date subject to any extensions of time which may be granted by the City. All work on the contract shall be completed by 15 months from NTP date.
    Liquidated damages in the amount of Five Hundred Dollars ($500.00) per consecutive calendar day will be assessed for each day that the Wastewater Collection System is not in operation after 12 months from NTP date with due allowance for extensions due to conditions beyond the control of the contractor. Liquidated damages in the amount of Five Hundred Dollars ($500.00) for each calendar day after 15 months from NTP date until all work in the contract is completed with due allowance for extensions due to conditions beyond the control of the contractor. Separate liquidated damage assessments may be made for each of the two completion dates.
    Payment of the cost of said project will be made from anyone or a combination of the following sources at the sole discretion of the Board of Alderman: (1) cash to be derived from the proceeds of the issuance and sale of Sewer Revenue Bonds or, which will be payable solely and only out of the future net revenues of the Municipal Sewer Fund, and/or from such other cash funds on hand of said Sewer Fund as may be lawfully used for said purpose; (2) cash derived from the proceeds of the issuance and sale of General Obligation Bonds of said City; (3) cash from such general funds of said City as may be legally used for such purpose; and (4) cash proceeds of a State Revolving Loan Fund.
    At least ten (10) days before each progress payment falls due (but not more often than once a month), the Contractor will submit to the Engineer a partial payment estimate filled out and signed by the Contractor covering the work performed during the period covered by the partial payment estimate and supported by such data as the Engineer may reasonably require. If payment is requested on the basis of materials and equipment not incorporated in the work but delivered and suitably stored at or near the site, the partial payment estimate shall also be accompanied by such supporting data, satisfactory to the Owner, as will establish the Owner’s title to the material and equipment. The Engineer will, within fifteen (15) days after receipt of each partial payment estimate, either indicate in writing his approval of payment and present the partial payment estimate to the Owner, or return the partial payment estimate to the Contractor indicating in writing his reasons for refusing to approve payment. In the latter case, the Contractor may make the necessary corrections and resubmit the partial payment estimate. The Owner will, within thirty (30) days of presentation to him of an approved partial payment estimate, pay the Contractor a progress payment on the basis of the approved partial payment estimate.
    The Owner shall retain five (5) percent of the amount of each payment as provided by Missouri regulations.
    The request for payment may also include an allowance for the cost of such major materials and equipment which are suitably stored either at or near the site.
    Prior to substantial completion, the Owner, with the approval of the Engineer and with the concurrence of the Contractor, may use any completed or substantially completed portions of the work. Such use shall not constitute an acceptance of such portions of the work.
    The Owner shall have the right to enter the premises for the purpose of doing work not covered by the contract documents. This provision shall not be construed as relieving the Contractor of the sole responsibility for the care and protection of the work, or the restoration of any damaged work except such as may be caused by agents or employees of the Owner.
    Upon completion and acceptance of the work, the Engineer shall issue a certificate that the work has been accepted by him under the conditions of the contract documents. Final payment will be made in accordance with the provisions of the Missouri regulations.
    The Contractor will indemnify and save the Owner or the Owner’s agents harmless from all claims growing out of the lawful demands of subcontractors, laborers, workmen, mechanics, materialmen, and furnishers of machinery and parts thereof, equipment, tools, and all supplies, incurred in the furtherance of the performance of the work. The Contractor shall furnish satisfactory evidence that all obligations of the nature designated above have been paid, discharged, or waived. If the Contractor fails to do so the Owner may, after having notified the Contractor, either pay unpaid bills or withhold from the Contractor’s unpaid compensation a sum of money deemed reasonably sufficient to pay any and all such lawful claims until satisfactory evidence is furnished that all liabilities have been fully discharged whereupon payment to the Contractor shall be resumed, in accordance with the terms of the contract documents, but in no event shall the provisions of this sentence be construed to impose any obligations upon the Owner to either the Contractor, his Surety, or any third party. In paying any unpaid bills of the Contractor, any payment so made by the Owner shall be considered as a payment made under the contract documents by the Owner to the Contractor and the Owner shall not be liable to the Contractor for any such payments made in good faith.
    Plans and specifications governing the construction of the proposed improvements have been prepared by VEENSTRA & KIMM, INC. of Liberty, Missouri, which plans and specifications and the proceedings of the Board of Alderman referring to and defining said improvements are hereby made a part of this notice and the proposed contract by reference, and the proposed contract shall be executed to comply therewith.
    Copies of said plans and specifications and form of contract are now on file in the office of the City Clerk. Copies may be obtained from VEENSTRA & KIMM, INC., 1201 West
College, Suite 100, Liberty, Missouri 64068 at a cost of $100.00.
    Published upon order of the Board of Alderman of the City of Lathrop, Missouri.
CITY OF LATHROP, Missouri
Dean Langner, Mayor
8/29c                                                                        Attest: Susie Freece, City Clerk

Notice of Entry
(supreme court rule 74.03)
In the 43’d Judicial Circuit Court, Clinton County, Missouri
207 North Main, Plattsburg, Missouri 64477
MIKE HARRIS ET Al V GREG MARTIN ET Al
CASE NO: 19CN-AC00253
Plaintiff: MIKE HARRIS
PO BOX 82
LATHROP< MO 64465
Filing date 12-Aug-2019
Service and Docket call set for 09-30-2019 a 10:00 AM
Event location: 207 North Main, Plattsburg, MO 64477
                                                                    8/22, 29, 9/5, 12c

Notice of Public Hearing  - Tax Levy Easton Fire Protection  District
    Notice is nearby given that the Easton Fire Protection District is holding a public hearing on Monday, August 28, at 7 p.m., to discuss the district’s tax levy. The public is welcome to attend. The address is 701 N. Buckling Drive, Easton, Mo.                             
                                                                                 8/22 & 29c

Notice of Public Hearing  - Tax Levy
THE HOLT COMMUNITY FIRE PROTECTION DISTRICT WILL CONDUCT A PUBLIC HEARING AT 7:00 P. M. ON TUESDAY AUGUST 26, 2018 TO APPROVE THE TAX LEVY AND BUDGET FOR 2020. THE MEETING WILL BE AT THE FIRE STATION, 260 N. 33 HWY, HOLT, MO 64048.
DISTRICT BOARD OF DIRECTORS                                             
                                                                                8/22 & 29c

NOTICE TO BIDDERS NOTICE OF TAKING BIDS FOR THE CONSTRUCTION OF WASTEWATER TREATMENT FACILITIES IMPROVEMENTS FOR  THE CITY OF LATHROP, MISSOURI
    Sealed proposals will be received by the City Clerk of the City of Lathrop, Missouri, at City Hall, 707 Oak Street, Lathrop, Missouri 64465, before 2:00 P.M. on the 3rd day of October, 2019 for the construction of the Wastewater Treatment Facilities Improvements as described in the plans and specifications therefore, now on file in the office of the City Clerk. Proposals will be opened and the amount of the bids announced by a City Representative at the time and date specified above. There will be a non-mandatory pre-bid meeting held at Brazelton Community Center, 707 Oak Street, Lathrop, Missouri 64465 on the 12th day of September, 2019 at 3:00 P.M.
    The location of the work to be done and the kinds and sizes of materials proposed to be used are as follows:
WASTEWATER TREATMENT FACILITIES IMPROVEMENTS
Construct improvements including all labor, materials and equipment necessary for excavation, backfill and sitework; lagoon cells with piping and associated equipment; demolition work; reinforced concrete; masonry building work including plumbing, heating, ventilating, doors, and associated work; painting; screening and grit removal equipment; pump station; ultraviolet disinfection equipment; blowers; electrical work including conduit, cables, wiring, motor controls, starters, switches, fixtures and controls; piping and appurtenances; and miscellaneous associated work, including cleanup.
    All work and materials are to be in accordance with the proposed plans, specifications, form of contract and estimate of cost now on file in the office of the City Clerk of Lathrop, Missouri, and by this reference made a part thereof as though fully set out and incorporated herein.
    All proposals and bids in connection therewith shall be submitted to the City Clerk of said City on or before the time herein set for receiving bids. All proposals shall be made on official bidding blanks furnished by the City, and any alterations in the official form of proposal will entitle the Board of Alderman, at its option, to reject the proposal involved from consideration. Each proposal shall be sealed and plainly identified.
    Each proposal shall be made out on a blank form furnished by the municipality and must be accompanied by bid security in a sealed envelope by either (1) a certified or cashier’s check drawn on a solvent Missouri chartered bank or a bank chartered under the laws of the United States, or a certified share draft drawn on a credit union in Missouri or chartered under the laws of the United States, in an amount equal to 5% of the bid, or (2) a bid bond executed by a corporation authorized to contract as a surety in the State of Missouri, in the penal sum of 5% of the bid.
    The bid security should be made payable to THE CITY OF LATHROP, MISSOURI. The bid security must not contain any conditions either in the body or as an endorsement thereon. The bid security shall be forfeited to the City as liquidated damages in the event the successful bidder fails or refuses to enter into a contract within 10 days after the award of contract and post bond satisfactory to the City insuring the faithful fulfillment of the contract and the maintenance of said work, if required, pursuant to the provisions of this notice and other contract documents. Bidders shall use the bid bond form included in the specifications.
    This project is financed through the Missouri State Revolving Fund (SRF), established by the sale of Missouri Water Pollution Control bonds and Federal Capitalization Grants to Missouri. SRF projects require compliance on several requirements that are explained in the contract documents including:
    • Prevailing wage rates
    • DBE (MBE/WBE)
    • EEO
    • Domestic Products Procurement Law Certification
    • American Iron and Steel Products
    The City of Lathrop is an Equal Opportunity Employer and invites the submission of bids from Women and Minority Business Enterprises.
Nondiscrimination in Employment
    Bidders will be required to comply with the President’s Executive Order No. 11246. The requirements for bidders and contractors under this order are explained in the specifications.
    Bidders will be required to take affirmative steps to involve Disadvantaged Business Enterprise (DBE) in the work under the contract. Bidders shall complete the applicable certification attached to the proposal. The certification shall include a listing of DBEs, the work and estimated dollar amount to be performed by each such enterprise, and the percentage of the total bid to be used for disadvantaged business enterprise(s). The bidder commits itself to the goals for DBE participation contained herein and all other requirements, terms and conditions of these bid conditions when it submits a properly signed bid.
    Any bidder or equipment supplier whose firm or affiliate is listed in the GSA publication “List of Parties Excluded from Federal Procurement and Nonprocurement Programs” will be prohibited from the bidding process. Anyone submitting a bid who is listed in this publication will be determined to be a nonresponsive bidder in accordance with 40 CFR Part 31.
    A Contractor’s Suspension/Debarment Certification will be contained in the specifications; however, this certification should not preclude any interested party from ascertaining whether the certifying person is actually on the “List of Parties Excluded from Federal Procurement and Nonprocurement Programs”. Bidders will be required to follow prevailing wage rate requirements. The prevailing wage rates table will be contained in the specifications.
    In accordance with Chapter 71.140, Missouri Revised Statues 1986, preference will be given to products and provisions grown and coal produced within the State of Missouri, and to Missouri domestic labor, to the extent lawfully required under Missouri Statutes; provided that the award of contract will be made to the lowest responsible bidder submitting the lowest responsive bid, which shall be determined without regard to state or local law whereby preference is given on factors other than the amount of the bid.
    The City reserves the right to reject any and all bids, for a sound, documented reason, to waive informalities and technicalities and to enter into such contract as it shall deem for the best interest of the City.
    The City reserves the right to defer acceptance of any proposal for a period not to exceed sixty (60) calendar days from the date of hearing.
    On the basis of the bids received, the Board of Alderman may propose award for the contract. Final award will not be made until the proposed award is approved by the Department of Natural Resources of the State of Missouri. It is anticipated that such approval will be made within thirty (30) days after application for approval of the proposed award. No claims for compensable delay shall arise as the result of delay in the approval of award.
    The successful bidder will be required to furnish separate performance and payment bonds each in an amount equal to one hundred percent (100%) of the contract price, are required by 10 CSR 20-4.040(18) on construction contracts of $100,000 or more. Where bonds are required, they must be obtained from companies holding certificates of authority as acceptable sureties (31 CFR Part 223).
    The work under the contract shall commence within ten (10) days after date set forth in written Notice to Proceed (NTP). The Wastewater Treatment Facility shall be in operation and treating wastewater by 18 months from NTP date subject to any
extensions of time which may be granted by the City. All work on the contract shall be completed by 24 months from NTP date.
    Liquidated damages in the amount of Five Hundred Dollars ($500.00) per consecutive calendar day will be assessed for each day that the Wastewater Treatment Facility is not in operation treating wastewater after 18 months from NTP date with due allowance for extensions due to conditions beyond the control of the contractor.
    Liquidated damages in the amount of Five Hundred Dollars ($500.00) for each calendar day after 24 months from NTP date until all work in the contract is completed with due allowance for extensions due to conditions beyond the control of the contractor. Separate liquidated damage assessments may be made for each of the two completion dates.
    Payment of the cost of said project will be made from anyone or a combination of the following sources at the sole discretion of the Board of Alderman: (1) cash to be derived from the proceeds of the issuance and sale of Sewer Revenue Bonds or, which will be payable solely and only out of the future net revenues of the Municipal Sewer Fund, and/or from such other cash funds on hand of said Sewer Fund as may be lawfully used for said purpose; (2) cash derived from the proceeds of the issuance and sale of General Obligation Bonds of said City; (3) cash from such general funds of said City as may be legally used for such purpose; and (4) cash proceeds of a State Revolving Loan Fund.
    At least ten (10) days before each progress payment falls due (but not more often than once a month), the Contractor will submit to the Engineer a partial payment estimate filled out and signed by the Contractor covering the work performed during the period covered by the partial payment estimate and supported by such data as the Engineer  may reasonably require. If payment is requested on the basis of materials and equipment not incorporated in the work but delivered and suitably stored at or near the site, the partial payment estimate shall also be accompanied by such supporting data, satisfactory to the Owner, as will establish the Owner’s title to the material and equipment. The Engineer will, within fifteen (15) days after receipt of each partial payment estimate, either indicate in writing his approval of payment and present the partial payment estimate to the Owner, or return the partial payment estimate to the Contractor indicating in writing his reasons for refusing to approve payment. In the latter case, the Contractor may make the necessary corrections and resubmit the partial payment estimate. The Owner will, within thirty (30) days of presentation to him of an approved partial payment estimate, pay the Contractor a progress payment on the basis of the approved partial payment estimate.
    The Owner shall retain five (5) percent of the amount of each payment as provided by Missouri regulations.
    The request for payment may also include an allowance for the cost of such major materials and equipment which are suitably stored either at or near the site.     
    Prior to substantial completion, the Owner, with the approval of the Engineer and with the concurrence of the Contractor, may use any completed or substantially completed portions of the work. Such use shall not constitute an acceptance of such portions of the work.
    The Owner shall have the right to enter the premises for the purpose of doing work not covered by the contract documents. This provision shall not be construed as relieving the Contractor of the sole responsibility for the care and protection of the work, or the restoration of any damaged work except such as may be caused by agents or employees of the Owner.
    Upon completion and acceptance of the work, the Engineer shall issue a certificate that the work has been accepted by him under the conditions of the contract documents. Final payment will be made in accordance with the provisions of the Missouri regulations.
    The Contractor will indemnify and save the Owner or the Owner’s agents harmless from all claims growing out of the lawful demands of subcontractors, laborers, workmen, mechanics, materialmen, and furnishers of machinery and parts thereof, equipment, tools, and all supplies, incurred in the furtherance of the performance of the work. The Contractor shall furnish satisfactory evidence that all obligations of the nature designated above have been paid, discharged, or waived. If the Contractor fails to do so the Owner may, after having notified the Contractor, either pay unpaid bills or withhold from the Contractor’s unpaid compensation a sum of money deemed reasonably sufficient to pay any and all such lawful claims until satisfactory evidence is furnished that all liabilities have been fully discharged whereupon payment to the Contractor shall be resumed, in accordance with the terms of the contract documents, but in no event shall the provisions of this sentence be construed to impose any obligations upon the Owner to either the Contractor, his Surety, or any third party. In paying any unpaid bills of the Contractor, any payment so made by the Owner shall be considered as a payment made under the contract documents by the Owner to the Contractor and the Owner shall not be liable to the Contractor for any such payments made in good faith.
    Plans and specifications governing the construction of the proposed improvements have been prepared by VEENSTRA & KIMM, INC. of Liberty, Missouri, which plans and specifications and the proceedings of the Board of Alderman referring to and defining said improvements are hereby made a part of this notice and the proposed contract by reference, and the proposed contract shall be executed to comply therewith.
    Copies of said plans and specifications and form of contract are now on file in the office of the City Clerk. Copies may be obtained from VEENSTRA & KIMM, INC, 1201 West College, Suite 100, Liberty, Missouri 64068 at a cost of $100.00.
    Published upon order of the Board of Alderman of the City of Lathrop, Missouri.
CITY OF LATHROP, Missouri
Dean Langner, Mayor
8/29c                                                                        Attest: Susie Freece, City Clerk

ADVERTISEMENT FOR BIDS
    Clinton County R3 School District of Plattsburg, Missouri will receive sealed bids at 800 W Frost St Plattsburg MO 64477, for furnishing all new materials and labor for STADIUM IMPROVEMENTS. The work includes, but is not limited to the following, all per the drawings and specifications.
    ● Site Improvements include: parking lot link, existing parking lot improvements, new parking lot, concessions plaza, sidewalks, and grading
    ● Construction of single wythe masonry field building that includes restrooms, concessions, and storage
    ● Providing and installing: prefabricated grandstand and pressbox, track and field event equipment, scoreboard, and playclocks
    Bids for all work will be received until 2:00 p.m., local time, on 11 SEPTEMBER, 2019, at which time they will be opened and publicly read aloud.
    There will be a Pre-Bid Conference on 05 SEPTEMBER, 2019 at 2:00 p.m., local time, at 800 W Frost St Plattsburg MO 64477. All interested parties must attend this Pre-Bid Conference. Contractors will be responsible for making site visits.
    Copies of the Bid Documents may be obtained from KC Blueprint & Planroom, www.kcblueprint.com, 816-527-0900, beginning at 2:00 p.m. on 28 August, 2019 .
                                                  8/29, 9/5c

NOTICE OF MEETING OF THE BOARD OF EDUCATION OF LATHROP R-II SCHOOL DISTRICT OF CLINTON COUNTY, MISSOURI TO CONSIDER A PROJECT PURSUANT TO SECTION 177.088, RSMO
    Public notice is hereby given that at a meeting to be held on Wednesday, September 11, 2019, at 7:00 p.m., the Board of Education of the Lathrop R-II School District of Clinton County, Missouri (the “District”), will consider and act upon the reaffirmation of a resolution approving a project including improvements at the Elementary School, pursuant to Section 177.088 of the Revised Statutes of Missouri, as amended (the “Act”). The project’s costs will be financed through an annually-renewable lease agreement to be entered into pursuant to the Act.
    The meeting will be held in the Board of Education Room at the District’s Administration Building, 700 East Street, in Lathrop, Missouri, and will be open to the public. Additional information regarding the proposed project and the financing thereof may be obtained in advance of the meeting from Chris Fine, Superintendent, Lathrop R-II School District, 300 East Street, Lathrop, Missouri 64465, phone (816) 740-3861.                                                   
                                                    8/22 & 29c

NOTICE OF TRUSTEE’S SALE
    A default has accrued on a certain note secured by a deed of trust executed by, Pamela D. Leer dated 8/30/2018 and recorded on 8/31/2018 in Instrument Number 201802470, in the Recorder’s office for Clinton County, Missouri. The successor trustee will on September 20, 2019 between the hours of 9:00 am and 5:00 pm, more particularly at 9:30 AM, at the West Front Door of the Clinton County Courthouse,  207 North Main, Plattsburg, Missouri sell at public venue to the highest bidder for cash (certified funds only), the following real estate:

ALL OF LOT THIRTY-TWO (32) IN VALLEY BROOK SUBDIVISION, A SUBDIVISION IN CAMERON, CLINTON COUNTY, MISSOURI.

Commonly known as: 1701 Prairie Circle, Cameron, Missouri 64429
    for the purpose of satisfying said indebtedness and the costs of executing this trust.
CSM Foreclosure Trustee Corp.
Successor Trustee
(800) 652-4080
4x 08/29/2019, 09/05/2019, 09/12/2019, 09/19/2019
CSM File 26-19-00355
NOTE: This office is a debt collector.
                                       8/29, 9/5, 12, 19c

IN THE CIRCUIT COURT OF CLINTON COUNTY, MISSOURI
PROBATE DIVISION
In the Estate of JACK H. CHEW, Deceased. Estate No. 18CN-PR00090
NOTICE OF FILING FINAL
STATEMENT OF ACCOUNT AND PROPOSED SCHEDULE OF DISTRIBUTION
    The undersigned Independent Personal Representative of the above captioned estate states that the undersigned will file a Final Statement of Account and a proposed schedule of distribution on September 5, 2019, or as may be continued by the court. If no objections to the account or the proposed schedule of distribution are filed within 20 days of the date the statement of account is filed, the undersigned will make distribution in accordance therewith. If no proceeding is filed against the undersigned within six months from the aforesaid date, the undersigned will be discharged from further claim or demand by any interested party.
Respectfully Submitted,
/s/ Jayson A. Watkins
Jayson A. Watkins Mo #61434
BROWN & WATKINS LLC
301 S. US 169 Hwy
Gower Missouri 64454
Tel: 816-424-1390
Fax: 816-424-1337
watkins@brownandwatkins.com
                                          8/8, 15, 22, 29c

NOTICE OF CHANGE OF NAME
TO WHOM IT MAY CONCERN: 19CN-DR00029
YOU ARE HEREBY NOTIFIED that by a Judgment entered on the 11th day of June, 2019 in the Circuit Court of Clinton County, State of Missouri, the name of Gunnar Filley Maxwell was changed to Gunnar Gene Filley.
ELLIS DOCKRAY CIRCUIT CLERK
BY: CONNIE THARP, SENIOR CLERK               
                                                                            8/22, 29, 9/5c

NOTICE OF TRUSTEEʼS SALE
    For default under the terms of the Deed of Trust executed by Fred T. Birch Jr. and Carolyn L. Birch, Husband and Wife, dated October 22, 2012, recorded on November 19, 2012 as Document No. 2012-3724, Office of the Recorder of Deeds, Clinton County, Missouri, the undersigned Successor Trustee will on Tuesday, September 17, 2019, at 09:30 AM at the West Front Door of the Clinton County Courthouse, 207 North Main, in Plattsburg, Missouri, sell at public vendue to the highest bidder for cash:
All of Lots Six (6) and Seven (7), in OREM`S SUBDIVISION of Lots Twelve (12) thru Fifteen (15), Eighteen (18) thru Twenty-one (21), in Block Thirty-seven (37), in the subdivision of Blocks Thirty-six (36), Thirty-seven (37), Forty-one (41) thru Forty-three (43), Forty-nine (49), Fifty-six (56) thru Sixty (60), in Lathrop, Clinton County, Missouri,

to satisfy said debt and costs.
Martin Leigh PC
Successor Trustee
Gregory D. Todd, Assistant Secretary
(816) 221-1430
www.martinleigh.com
(Birch, 5898.048, Publication Start: 08/22/2019 )

MARTIN LEIGH PC, AS SUCCESSOR TRUSTEE, IS ATTEMPTING TO COLLECT A DEBT AND ANY  INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
                                                                      8/22, 29, 9/5, 12c

 NOTICE OF TRUSTEE’S SALE
    A default has accrued on a certain note secured by a deed of trust executed by, Delbert Stalder AND Louise W. Stalder dated 5/8/2012 and recorded on 6/1/2012 as Document number 2012-1768, in the Recorder’s office for Clinton County, Missouri. The successor trustee will on September 20, 2019 between the hours of 9:00 am and 5:00 pm, more particularly at 9:30AM, at the West Front Door of the Clinton County Courthouse,  207 North Main, Plattsburg, Missouri sell at public venue to the highest bidder for cash (certified funds only), the following real estate:

BEGINNING AT THE SOUTHWEST CORNER OF LOT THREE (3) IN BLOCK ONE (1), PLATTSBURG LAND AND BUILDING ASSOCIATION ADDITION TO THE CITY OF PLATTSBURG, CLINTON COUNTY, MISSOURI; THENCE ALONG THE WEST LINE OF SAID LOT NORTH 00 DEGREES 01’34” EAST, 87.70 FEET; THENCE SOUTH 89 DEGREES 48’38” EAST, 96.33 FEET TO THE EAST LINE OF SAID LOT; THENCE ALONG SAID LINE SOUTH 00 DEGREES, 01’34” WEST, 87.70 FEET TO THE SOUTHEAST CORNER OF SAID LOT; THENCE ALONG THE SOUTH LINE OF SAID LOT NORTH 89 DEGREES, 48’38” WEST, 96.33 FEET TO THE POINT OF BEGINNING.  
ALSO
THE SOUTH ONE FOOT OF THE FOLLOWING DESCRIBED TRACT OF LAND: ALL THAT PART OF LOT THREE(3) IN BLOCK ONE (1) OF THE CITY OF PLATTSBURG LAND AND BUILDING ASSOCIATION ADDITION TO THE CITY OF PLATTSBURG, CLINTON COUNTY, MISSOURI DESCRIBED AS FOLLOWS: COMMENCING AT THE SOUTHWEST CORNER OF LOT THREE (3) IN BLOCK ONE (1), PLATTSBURG LAND AND BUILDING ASSOCIATION ADDITION TO THE CITY OF PLATTSBURG, CLINTON COUNTY, MISSOURI; THENCE ALONG THE WEST LINE OF SAID LOT NORTH 00 DEGREES 01’34” EAST, 87.70 FEET TO THE POINT OF BEGINNING; THENCE CONTINUING ALONG SAID LINE NORTH 00 DEGREES, 01’34” EAST, 62.30 FEET TO THE NORTHWEST CORNER OF SAID LOT; THENCE SOUTH 89 DEGREES 48’38” EAST ALONG THE NORTH LINE OF SAID LOT 96.33 FEET TO THE NORTHEAST CORNER OF SAID LOT; THENCE ALONG THE EAST LINE OF SAID LOT SOUTH 00 DEGREES 01’34” WEST, 62.30 FEET; THENCE NORTH 89 DEGREES 48’38” WEST, 96.33 FEET TO THE POINT OF BEGINNING.

Commonly known as: 214 W. Clay Ave., Plattsburg, Missouri 64477
    for the purpose of satisfying said indebtedness and the costs of executing this trust.
CSM Foreclosure Trustee Corp.
Successor Trustee
(800) 652-4080
4x 08/29/2019, 09/05/2019, 09/12/2019, 09/19/2019
CSM File 26-18-00100
NOTE: This office is a debt collector.
                                                                      8/29, 9/5, 12, 19c