Legals

Legals (02.20.20)

2/20/2020

PUBLIC HEARING
Trevor McCrary has applied for a Replat to combine Lots 23 & 24 of Centennial Acres Subdivision. Property is located South of Z Highway, West of 169 Highway in Section 15, Township 54N, Range 33W. The Public Hearing will be held March 5th, 2020 at 7:00 pm in the Community Room of the Clinton County Courthouse. All interested parties should attend 2/20, 27c

PUBLIC HEARING
Terry Bush of Lathrop, MO has applied to the Clinton County Planning and Zoning Commission for a Special Use Permit for an Event Center located on the South side of SE 216th Street, West of W HWY, East of SE Atchison Rd at 1315 SE 216th Street, Lathrop MO in Section 21, Township 54N, Range 31W. The Public Hearing will be held Thursday, March 5, 2020 at 7:00 pm in the Community room in the basement of the Clinton County Courthouse. All interested parties should attend. 2/20, 27c

BID NOTICE FOR FOR 2020 LAWN AND SNOW CARE
TRI-COUNTY AMBULANCE DISTRICT
1703 W HIGHWAY 116,
PLATTSBURG, MO 64477
Tri-County Ambulance District will be accepting sealed bids for lawn care maintenance and snow/ice removal for the 2020 spring-winter season on an as needed basis. Bidders must be 18 years of age or older and must provide liability insurance. If you are interested please send bids to 1703 W Highway 116, Plattsburg, MO 64477 by February 27th, 2020. Bids will be reviewed by the Board of Directors at the regular board meeting. 1/30, 2/6, 13, 20c

NOTICE OF TRUSTEE’S SALE

   In Cause No. 17CN-CV00779 in the Circuit Court of Clinton County, State of Missouri, a judgment was entered on December 12, 2019 and recorded on January 10, 2020 in favor of Nationstar Mortgage LLC for judgment and for enforcement of Deed of Trust executed by Robert G. Swallow and Beverly A Swallow, dated June 24, 2009 and recorded on July 22, 2009 as Document No. 2009-2294, Office of Recorder of Deeds, Clinton County, Missouri. The Successor Trustee will on March 6, 2020, between the hours of 9:00 o’clock A.M. and 5:00 P.M. more particularly at 10:00AM, at the Clinton County Courthouse, 211 North Main St., West Front door, Plattsburg, MO 64477, sell at public venue to the highest bidder for cash, the following real estate:

All of the South half of block three (3), in the Town of Perrin, Clinton County, Missouri.

For the purpose of satisfying said indebtedness and the costs of executing this trust.

S&W Foreclosure Corporation
Successor Trustee
Pub Commences February 13, 2020
S&K File No.17-031063
By: Shapiro & Kreisman, LLC
www.logs.com/shapiro_kreisman_missouri
Auction.com
Purported address:   28 NW Tyer Lane, Plattsburg, MO 64477
Publication Dates: 02/13/20, 02/20/20, 02/27/20, 03/05/20
                                      2/13, 20, 27, 3/5c

PUBLIC HEARING
Joseph McGinness of Lathrop, MO has applied to the Clinton County Planning and Zoning Commission for a Replat and Rezone of 46.17 acres located in the Southwest Quadrant of Stonum Road and 116 HWY, West of Stonum Road and South of 116 HWY, Lathrop MO in Section 28, Township 55N, Range 30W. The Public Hearing will be held Thursday, March 5, 2020 at 7:00 pm in the Community Room in the basement of the Clinton County Courthouse. All interested parties should attend. 2/20, 27c

PUBLIC HEARING
Anne Martin of Lathrop, MO and Ann Sires of Camden Point, MO have applied to the Clinton County Planning and Zoning Commission for a Subdivision of 30.890-acres into 2 parcels; Rezoning 10-acres from AG-A to AG-B. Property is located North of SE 216th Street on the East side of W Highway, Lathrop MO. Section 15; Township 54N; Range 31W. The Public Hearing will be held March 5th, 2020 at 7:00 pm in the Community Room of the Clinton County Courthouse. All interested parties should attend. 2/20, 27c

In Re: Scott Sapp and Sarah Sapp, husband and wife

TRUSTEE’S SALE – Under the terms of the Deed of Trust executed by Scott Sapp and Sarah Sapp, husband and wife dated 06/10/2016, and recorded on 06/16/2016 Document 201601622 in the office of the Recorder of Deeds for Clinton County, MISSOURI, the undersigned Successor Trustee, will on 02/21/2020 at 3:00 PM at the West Front Door of the Clinton County Courthouse, 207 N. Main St. Plattsburg MO 64477, sell at public venue to the highest bidder for cash subject to the terms announced at the sale, the realty described in said deed of trust, to wit:

THAT PORTION OF THE SOUTH HALF OF SECTION THIRTEEN (13), TOWNSHIP FIFTY-FOUR (54) NORTH, RANGE THIRTY-ONE (31) WEST OF THE FIFTH PRINCIPAL MERIDIAN, CLINTON COUNTY, MISSOURI DESCRIBED AS FOLLOWS: COMMENCING AT THE CENTER OF SAID SECTION THIRTEEN (13), THENCE NORTH 89 DEGREES 29 MINUTES 09 SECONDS EAST, 612.88 FEET ALONG THE NORTH LINE OF SAID SOUTH HALF; THENCE SOUTH 20 DEGREES 07 MINUTES 35 SECONDS WEST, 1245.98 FEET TO THE POINT OF BEGINNING OF THE TRACT OF LAND TO BE HEREIN DESCRIBED; THENCE WEST 757.14 FEET TO THE EAST RIGHT-OF-WAY LINE OF MISSOURI HIGHWAY 33; THENCE SOUTH 19 DEGREES 59 MINUTES 58 SECONDS WEST, 577.68 FEET ALONG SAID RIGHT-OF-WAY LINE; THENCE EAST, 929.13 FEET; THENCE NORTH 03 DEGREES 00 MINUTES 50 SECONDS EAST, 543.59 FEET TO THE POINT OF BEGINNING, EXCEPTING THEREFROM A TRACT OF LAND DESCRIBED AS FOLLOWS, TO WIT: BEGINNING AT THE CENTER OF SAID SECTION THIRTEEN (13); THENCE NORTH 89 DEGREES 29 MINUTES 09 SECONDS EAST, 612.88 FEET ALONG THE NORTH LINE OF SAID SOUTH HALF; THENCE SOUTH 20 DEGREES 07 MINUTES 35 SECONDS WEST, 1245.98 FEET, THENCE SOUTH 03 DEGREES 00 MINUTES 50 SECONDS WEST, 543.59 FEET; TO THE TRUE POINT OF BEGINNING; THENCE WEST 926.13 FEET TO THE EAST RIGHT-OF-WAY LINE OF MISSOURI HIGHWAY 33; THENCE NORTH 19 DEGREES 59 MINUTES 58 SECONDS EAST, 147.00 FEET ALONG SAID RIGHT-OF-WAY LINE; THENCE IN A SOUTHEASTERLY DIRECTION TO THE TRUE POINT OF BEGINNING. SUBJECT TO THAT PART, IF ANY, IN ANY STREETS, ROADWAYS, HIGHWAYS OR OTHER RIGHT-OF-WAYS..

Substitute Trustee Corporation
SUCCESSOR TRUSTEE
HYPERLINK “http://www.substitutetrusteecorp.com/”www.substitutetrusteecorp.com

Published in the Clinton County Leader
File #: SAPSACHL
First publication date 01/30/2020
*__12464039__*
1/30, 2/6, 13, 20c

PUBLIC HEARING
Curtis Foster of Trimble, MO has applied for a Replat of 17.95 acres into two parcels equaling 6.34 acres and 11.61 acres; Rezoning said lots to Ag-B. Property is located West of 169 Highway, North of SW 208th Street in the Clinton Estates Subdivision, Section 23, Township 54N, Range 33W. The Public Hearing will be held March 5th, 2020 at 7:00 pm in the Community Room of the Clinton County Courthouse. All interested parties should attend 2/20, 27c

Notice of Trustee’s Sale
For default in payment of debt and performance of obligations secured by a Deed of Trust executed by Steve Harrison and Julie St. Louis, husband and wife, and Peggy J. Chocholousek, a single person, dated April 15, 2008, filed April 21, 2008, and recorded as Document No. 2008-1309, in Book 2008, at Page 1309, in the Office of the Recorder of Deeds for Clinton County, Missouri, at Plattsburg, the undersigned Trustee, John M. Crossett, at the request of the legal holder of said indebtedness (which indebtedness is now fully due, payable and mature), will on February 21, 2020, between the hours of 9:00 A.M. and 5:00 P.M, at the West front door of the Clinton County Circuit Courthouse in Plattsburg, Missouri, sell at public vendue to the highest cash bidder, the realty described in said Deed of Trust, to wit:

Lot Three (3), in Valleyview Estates, an addition to the City of Plattsburg, Clinton County, Missouri, as per recorded plat thereof,

to satisfy said debt and cost. The precise time of sale shall be 2:00 PM or as soon thereafter as such sale may reasonably be called.
John M. Crossett, Trustee
1/30, 2/6, 13, 20c

TRUSTEE’S SALE
IN RE: Lawrence D Geary, a married person, and Deborah K. Geary, nontitled spouse joining as to marital/homestead rights only Trustee’s Sale:

For default in payment of debt and performance of obligation secured by Deed of Trust executed by Lawrence D Geary, a married person, and Deborah K. Geary, nontitled spouse joining as to marital/homestead rights only dated March 6, 2015 and recorded in the Office of the Recorder of Deeds of Clinton County, Missouri as Document Number 2015-724 the undersigned Successor Trustee, at the request of the legal holder of said Note will on Monday, February 24, 2020 between the hours of 9:00 a.m. and 5:00 p.m., (at the specific time of 12:50 PM), at the West Front Door of the Court House, City of Plattsburg, County of Clinton, State of Missouri, sell at public vendue to the highest bidder for cash the following described real estate, described in said Deed of Trust, and situated in Clinton County, State of Missouri, to wit:
A TRACT OF LAND IN THE WEST HALF OF THE SOUTHWEST QUARTER OF SECTION FOURTEEN (14), IN TOWNSHIP FIFTY-FIVE (55), OF RANGE THIRTY-THREE (33), CLINTON COUNTY, MISSOURI, MORE PARTICULARLY DESCRIBED AS FOLLOWS: BEGINNING AT THE SOUTHWEST CORNER OF THE SAID SECTION FOURTEEN (14), TOWNSHIP FIFTY-FIVE (55), RANGE THIRTY-THREE (33), CLINTON COUNTY, MISSOURI; THENCE EAST ALONG THE SOUTH LINE OF SAID SECTION FOURTEEN (14), 243 FEET; THENCE NORTH 573 FEET; THENCE WEST 243 FEET TO THE WEST BOUNDARY OF SAID SECTION FOURTEEN (14); THENCE SOUTH 573 FEET ALONG THE WEST LINE OF SAID SECTION FOURTEEN (14), TO THE POINT OF BEGINNING.

to satisfy said debt and cost.
MILLSAP & SINGER, P.C.,
Successor Trustee
612 Spirit Drive
St. Louis, MO 63005
(636) 537-0110
File No: 200992.022420.406211 FC

Notice
Pursuant to the Fair Debt Collection Practices Act, 15 U.S.C. §1692c(b), no information concerning the collection of this debt may be given without the prior consent of the consumer given directly to the debt collector or the express permission of a court of competent jurisdiction. The debt collector is attempting to collect a debt and any information obtained will be used for that purpose.

PUBLISH ON: January 30, 2020 02/06/2020, 02/13/2020, 02/20/2020
1/30, 2/6, 13, 20c

NOTICE OF PUBLIC HEARING

The Lathrop Planning and Zoning Commission will hold a public hearing on March 9, 2020 at 7:00 PM in the Betty Brazelton Community Center at the Lathrop City Hall. The purpose of the hearing is to allow public participation in considering the zoning change request from Single-Family Residential to Multi-Family Residential for Lot 10 of Lariat Heights 2nd Plat, on the north side of Concha Street near the intersection of Lariat and Concha Streets. The legal description of the property is as follows:

Lot Ten (10), LARIAT HEIGHTS SECOND PLAT, a subdivision in the City of Lathrop, Clinton County, Missouri. Subject to easements, restrictions, roadways and reservations of record.

Bob Burns, City Administrator
2/20c

NOTICE TO BIDDERS

NOTICE OF TAKING BIDS FOR THE CONSTRUCTION OF WASTEWATER TREATMENT FACILITIES IMPROVEMENTS FOR THE CITY OF LATHROP, MISSOURI

   Sealed proposals will be received by the City Clerk of the City of Lathrop, Missouri, at City Hall, 707 Oak Street, Lathrop, Missouri 64465, before 2:00 P.M. on the 26th day of March, 2020 for the construction of the Wastewater Treatment Facilities Improvements as described in the plans and specifications therefore, now on file in the office of the City Clerk. Proposals will be opened and the amount of the bids announced by a City Representative at the time and date specified above. There will be a non-mandatory pre-bid meeting held at Brazelton Community Center, 707 Oak Street, Lathrop, Missouri 64465 on the 9th day of March, 2020 at 11:00 A.M.
   The location of the work to be done and the kinds and sizes of materials proposed to be used are as follows:

WASTEWATER TREATMENT FACILITIES IMPROVEMENTS

Construct improvements including all labor, materials and equipment necessary for excavation, backfill and sitework; lagoon cells with piping and associated equipment; demolition work; reinforced concrete; pre-engineered building work including heating, ventilating, doors, and associated work; painting; pump station; ultraviolet disinfection equipment; blowers; electrical work including conduit, cables, wiring, motor controls, starters, switches, fixtures and controls; piping and appurtenances; and miscellaneous associated work, including cleanup.

   All work and materials are to be in accordance with the proposed plans, specifications, form of contract and estimate of cost now on file in the office of the City Clerk of Lathrop, Missouri, and by this reference made a part thereof as though fully set out and incorporated herein.
   All proposals and bids in connection therewith shall be submitted to the City Clerk of said City on or before the time herein set for receiving bids. All proposals shall be made on official bidding blanks furnished by the City, and any alterations in the official form of proposal will entitle the Board of Alderman, at its option, to reject the proposal involved from consideration. Each proposal shall be sealed and plainly identified.
   Each proposal shall be made out on a blank form furnished by the municipality and must be accompanied by bid security in a sealed envelope by either (1) a certified or cashier’s check drawn on a solvent Missouri chartered bank or a bank chartered under the laws of the United States, or a certified share draft drawn on a credit union in Missouri or chartered under the laws of the United States, in an amount equal to 5% of the bid, or (2) a bid bond executed by a corporation authorized to contract as a surety in the State of Missouri, in the penal sum of 5% of the bid.
   The bid security should be made payable to THE CITY OF LATHROP, MISSOURI. The bid security must not contain any conditions either in the body or as an endorsement thereon. The bid security shall be forfeited to the City as liquidated damages in the event the successful bidder fails or refuses to enter into a contract within 10 days after the award of contract and post bond satisfactory to the City insuring the faithful fulfillment of the contract and the maintenance of said work, if required, pursuant to the provisions of this notice and other contract documents. Bidders shall use the bid bond form included in the specifications.
   This project is financed through the Missouri State Revolving Fund (SRF), established by the sale of Missouri Water Pollution Control bonds and Federal Capitalization Grants to Missouri. SRF projects require compliance on several requirements that are explained in the contract documents including:

   •   Prevailing wage rates
   •   DBE (MBE/WBE)
   •   EEO
   •   Domestic Products Procurement Law Certification
   •   American Iron and Steel Products

   The City of Lathrop is an Equal Opportunity Employer and invites the submission of bids from Women and Minority Business Enterprises.

Nondiscrimination in Employment

   Bidders will be required to comply with the President’s Executive Order No. 11246. The requirements for bidders and contractors under this order are explained in the specifications.
   Bidders will be required to take affirmative steps to involve Disadvantaged Business Enterprise (DBE) in the work under the contract. Bidders shall complete the applicable certification attached to the proposal. The certification shall include a listing of DBEs, the work and estimated dollar amount to be performed by each such enterprise, and the percentage of the total bid to be used for disadvantaged business enterprise(s). The bidder commits itself to the goals for DBE participation contained herein and all other requirements, terms and conditions of these bid conditions when it submits a properly signed bid.
   Any bidder or equipment supplier whose firm or affiliate is listed in the GSA publication “List of Parties Excluded from Federal Procurement and Nonprocurement Programs” will be prohibited from the bidding process. Anyone submitting a bid who is listed in this publication will be determined to be a nonresponsive bidder in accordance with 40 CFR Part 31.
   A Contractor’s Suspension/Debarment Certification will be contained in the specifications; however, this certification should not preclude any interested party from ascertaining whether the certifying person is actually on the “List of Parties Excluded from Federal Procurement and Nonprocurement Programs”.
   Bidders will be required to follow prevailing wage rate requirements. The prevailing wage rates table will be contained in the specifications.
   In accordance with Chapter 71.140, Missouri Revised Statues 1986, preference will be given to products and provisions grown and coal produced within the State of Missouri, and to Missouri domestic labor, to the extent lawfully required under Missouri Statutes; provided that the award of contract will be made to the lowest responsible bidder submitting the lowest responsive bid, which shall be determined without regard to state or local law whereby preference is given on factors other than the amount of the bid.
   The City reserves the right to reject any and all bids, for a sound, documented reason, to waive informalities and technicalities and to enter into such contract as it shall deem for the best interest of the City.
   The City reserves the right to defer acceptance of any proposal for a period not to exceed sixty (60) calendar days from the date of hearing.
   On the basis of the bids received, the Board of Alderman may propose award for the contract. Final award will not be made until the proposed award is approved by the Department of Natural Resources of the State of Missouri. It is anticipated that such approval will be made within thirty (30) days after application for approval of the proposed award. No claims for compensable delay shall arise as the result of delay in the approval of award.
   The successful bidder will be required to furnish separate performance and payment bonds each in an amount equal to one hundred percent (100%) of the contract price, are required by 10 CSR 20-4.040(18) on construction contracts of $100,000 or more. Where bonds are required, they must be obtained from companies holding certificates of authority as acceptable sureties (31 CFR Part 223).
   The work under the contract shall commence within ten (10) days after date set forth in written Notice to Proceed (NTP). The Wastewater Treatment Facility shall be in operation and treating wastewater by 18 months from NTP date subject to any extensions of time which may be granted by the City. All work on the contract shall be completed by 24 months from NTP date.
   Liquidated damages in the amount of Five Hundred Dollars ($500.00) per consecutive calendar day will be assessed for each day that the Wastewater Treatment Facility is not in operation treating wastewater after 18 months from NTP date with due allowance for extensions due to conditions beyond the control of the contractor.
   Liquidated damages in the amount of Five Hundred Dollars ($500.00) for each calendar day after 24 months from NTP date until all work in the contract is completed with due allowance for extensions due to conditions beyond the control of the contractor. Separate liquidated damage assessments may be made for each of the two completion dates.
   Payment of the cost of said project will be made from any one or a combination of the following sources at the sole discretion of the Board of Alderman: (1) cash to be derived from the proceeds of the issuance and sale of Sewer Revenue Bonds or, which will be payable solely and only out of the future net revenues of the Municipal Sewer Fund, and/or from such other cash funds on hand of said Sewer Fund as may be lawfully used for said purpose; (2) cash derived from the proceeds of the issuance and sale of General Obligation Bonds of said City; (3) cash from such general funds of said City as may be legally used for such purpose; and (4) cash proceeds of a State Revolving Loan Fund.
   At least ten (10) days before each progress payment falls due (but not more often than once a month), the Contractor will submit to the Engineer a partial payment estimate filled out and signed by the Contractor covering the work performed during the period covered by the partial payment estimate and supported by such data as the Engineer may reasonably require. If payment is requested on the basis of materials and equipment not incorporated in the work but delivered and suitably stored at or near the site, the partial payment estimate shall also be accompanied by such supporting data, satisfactory to the Owner, as will establish the Owner’s title to the material and equipment. The Engineer will, within fifteen (15) days after receipt of each partial payment estimate, either indicate in writing his approval of payment and present the partial payment estimate to the Owner, or return the partial payment estimate to the Contractor indicating in writing his reasons for refusing to approve payment. In the latter case, the Contractor may make the necessary corrections and resubmit the partial payment estimate. The Owner will, within thirty (30) days of presentation to him of an approved partial payment estimate, pay the Contractor a progress payment on the basis of the approved partial payment estimate.
   The Owner shall retain five (5) percent of the amount of each payment as provided by Missouri regulations.
   The request for payment may also include an allowance for the cost of such major materials and equipment which are suitably stored either at or near the site.
   Prior to substantial completion, the Owner, with the approval of the Engineer and with the concurrence of the Contractor, may use any completed or substantially completed portions of the work. Such use shall not constitute an acceptance of such portions of the work.
   The Owner shall have the right to enter the premises for the purpose of doing work not covered by the contract documents. This provision shall not be construed as relieving the Contractor of the sole responsibility for the care and protection of the work, or the restoration of any damaged work except such as may be caused by agents or employees of the Owner.
   Upon completion and acceptance of the work, the Engineer shall issue a certificate that the work has been accepted by him under the conditions of the contract documents. Final payment will be made in accordance with the provisions of the Missouri regulations.
   The Contractor will indemnify and save the Owner or the Owner’s agents harmless from all claims growing out of the lawful demands of subcontractors, laborers, workmen, mechanics, materialmen, and furnishers of machinery and parts thereof, equipment, tools, and all supplies, incurred in the furtherance of the performance of the work. The Contractor shall furnish satisfactory evidence that all obligations of the nature designated above have been paid, discharged, or waived. If the Contractor fails to do so the Owner may, after having notified the Contractor, either pay unpaid bills or withhold from the Contractor’s unpaid compensation a sum of money deemed reasonably sufficient to pay any and all such lawful claims until satisfactory evidence is furnished that all liabilities have been fully discharged whereupon payment to the Contractor shall be resumed, in accordance with the terms of the contract documents, but in no event shall the provisions of this sentence be construed to impose any obligations upon the Owner to either the Contractor, his Surety, or any third party. In paying any unpaid bills of the Contractor, any payment so made by the Owner shall be considered as a payment made under the contract documents by the Owner to the Contractor and the Owner shall not be liable to the Contractor for any such payments made in good faith.
   Plans and specifications governing the construction of the proposed improvements have been prepared by VEENSTRA & KIMM, INC. of Liberty, Missouri, which plans and specifications and the proceedings of the Board of Alderman referring to and defining said improvements are hereby made a part of this notice and the proposed contract by reference, and the proposed contract shall be executed to comply therewith.
   Copies of said plans and specifications and form of contract are now on file in the office of the City Clerk. Copies may be obtained from VEENSTRA & KIMM, INC., 1201 West College, Suite 100, Liberty, Missouri 64068 at a cost of $100.00.
   Published upon order of the Board of Alderman of the City of Lathrop, Missouri.

CITY OF LATHROP, MISSOURI
Dean Langner, Mayor

ATTEST:
Susie Freece, City Clerk
                                                                                                                             2/20c

IN THE 43RD JUDICIAL CIRCUIT COURT, CLINTON COUNTY, MISSOURI
PROBATE Division Case Number: 20CN-PR00003
In the Estate of JOHN M. BARRY, Deceased.
Notice of Letters of Administration Granted
(Independent Administration)
   To All Persons Interested in the Estate of JOHN M. BARRY, Decedent:
   On FEBRUARY 6, 2020, the following individual was appointed the personal representative of the estate of JOHN M. BARRY, decedent, by the Probate Division of the Circuit Court of Clinton County, Missouri. The personal representative’s business address is: KELLY JO BEAL, 524 W. FOURTH STREET, CAMERON, MO 64429
   The personal representative may administer the estate independently without adjudication, order, or direction of the Probate Division of the Circuit Court, unless a petition for supervised administration is made to and granted by the court.
   The personal representative’s attorney’s name, business address and phone number is: TROY L. DIETRICH, 416 N. WALNUT, CAMERON, MO 64429 (816) 632-3033
   All creditors of said decedent are notified to file claims in court within six months from the date of the first publication of this notice or if a copy of this notice was mailed to, or served upon, such creditor by the personal representative, then within two months from the date it was mailed or served, whichever is later, or be forever barred to the fullest extent permissible by law. Such six-month period and such two-month period do not extend the limitation period that would bar claims one year after the decedent’s death, as provided in Section 473.444, RSMo, or any other applicable limitation periods. Nothing in Section 473.033, RSMo, shall be construed to bar any action against a decedent’s liability insurance carrier through a defendant ad litem pursuant to Section 537.021, RSMo.
   Date of the Decedent’s Death: NOVEMBER 19, 2019
   Date of first publication: FEBRUARY 13, 2020
ELLIS DOCKRAY, CIRCUIT CLERK
By: Nancy Kelly, Probate Clerk
   Receipt of this notice by mail should not be construed by the recipient to indicate that the recipient necessarily has a beneficial interest in the estate. The nature and extent of any person’s interest, if any, can be determined from the files and records of this estate in the Probate Division of the above referenced Circuit Court.                                                                              2/13, 20, 27, 3/5c

IN THE 43RD JUDICIAL CIRCUIT COURT, CLINTON COUNTY, MISSOURI
Probate Division: Case Number: 20CN-PR00002
In the Estate of SUSAN ELAINE TINGLEY, Deceased.
Notice of Letters of Administration Granted
(Independent Administration - Non Resident Fiduciary)
   To All Persons Interested in the Estate of SUSAN ELAINE TINGLEY, Decedent: On FEBRUARY 6, 2020, the following individual was appointed the personal representative of the estate of SUSAN ELAINE TINGLEY, decedent, by the Probate Division of the Circuit Court of Clinton County, Missouri. The personal representative’s business address is: JANICE ELEANOR ADAMS, 425 HURFVILLE-CROSSKEYS ROAD #8265, TURNERSVILLE, NEW JERSEY 08012. The personal representative may administer the estate independently without adjudication, order, or direction of the Probate Division of the Circuit Court, unless a petition for supervised administration is made to and granted by the court.
   The personal representative’s attorney’s name, business address and phone number is: RICHARD J. HERNDON, 455 SAM BARR DRIVE, SUITE 207, KEARNEY, MISSOURI 64060 (816) 628-4900
   The Non-Resident Personal Representative’s designated agent’s name, business address, and phone number is: RICHARD J. HERNDON, 14218 Mark Drive, Kearney, Missouri 64060.
   All creditors of said decedent are notified to file claims in court within six months from the date of the first publication of this notice or if a copy of this notice was mailed to, or served upon, such creditor by the personal representative, then within two months from the date it was mailed or served, whichever is later, or be forever barred to the fullest extent permissible by law. Such six-month period and such two-month period do not extend the limitation period that would bar claims one year after the decedent’s death, as provided in Section 473.444, RSMo, or any other applicable limitation periods. Nothing in Section 473.033, RSMo, shall be construed to bar any action against a decedent’s liability insurance carrier through a defendant ad
litem pursuant to Section 537.021, RSMo.
   Date of the Decedent’s Death: MARCH 19, 2019
   Date of first publication: FEBRUARY 13, 2020
ELLIS DOCKRAY, CIRCUIT CLERK
By: Nancy Kelly, Probate Clerk
Receipt of this notice by mail should not be construed by the recipient to indicate that the recipient necessarily has a beneficial interest in the estate. The nature and extent of any person’s interest, if any, can be determined from the files and records of this estate in the Probate Division of the above referenced Circuit Court.                             2/13, 20, 27, 3/5c

IN THE 43RD JUDICIAL CIRCUIT COURT, CLINTON COUNTY, MISSOURI
Probate Division:
Case Number: 20CN-PR00004
In the Estate of LEANN GUMP, Deceased.
Notice of Letters of Administration Granted
(Independent Administration)
   To All Persons Interested in the Estate of LEANN GUMP, Decedent: On FEBRUARY 6, 2020, the following individual was appointed the personal representative of the estate of LEANN GUMP, decedent, by the Probate Division of the Circuit Court of Clinton County, Missouri. The personal representative’s business address is: JESSICA GUMP, APT. Q302, 2900 WILLIAMSBURG TERRACE, PLATTE CITY, MO 64079
   The personal representative may administer the estate independently without adjudication, order, or direction of the Probate Division of the Circuit Court, unless a petition for supervised administration is made to and granted by the court.
   The personal representative’s attorney’s name, business address and phone number is: KIM BROWN, 1803 N. WALNUT, P. O. BOX 77, CAMERON, MO 64429
   All creditors of said decedent are notified to file claims in court within six months from the date of the first publication of this notice or if a copy of this notice was mailed to, or served upon, such creditor by the personal representative, then within two months from the date it was mailed or served, whichever is later, or be forever barred to the fullest extent permissible by law. Such six-month period and such two-month period do not extend the limitation period that would bar claims one year after the decedent’s death, as provided in Section 473.444, RSMo, or any other applicable limitation periods. Nothing in Section 473.033, RSMo, shall be construed to bar any action against a decedent’s liability insurance carrier through a defendant ad litem pursuant to Section 537.021, RSMo.
   Date of the Decedent’s Death: FEBRUARY 2, 2019
   Date of first publication: FEBRUARY 13, 2020
ELLIS DOCKRAY, CIRCUIT CLERK
By: Nancy Kelly, Probate Clerk
Receipt of this notice by mail should not be construed by the recipient to indicate that the recipient necessarily has a beneficial interest in the estate. The nature and extent of any person’s interest, if any, can be determined from the files and records of this estate in the Probate Division of the above referenced Circuit Court.                                               2/13, 20, 27, 3/5c

NOTICE OF TRUSTEE’S SALE
For default in the payment of debt and performance of an obligation secured by a Deed of Trust, executed by RODNEY LONG, a/k/a RODNEY R. LONG, and RITA LONG, a/k/a RITA M. LONG, husband and wife, dated November 10, 2005, recorded as Document No. 2005-5573, in the Office of the Recorder of Deeds of Clinton County, Missouri, the undersigned Trustee, will, on Wednesday, March 18, 2020, between the hours of 9:00 a.m., and 5:00 p.m., and specifically at 2:00 p.m., at the West front door of the Clinton County Courthouse in Plattsburg, Clinton County, Missouri, sell at public vendue to the highest bidder for cash, the real estate, legally described in the Deed of Trust, located in Clinton County, Missouri, as follows:

Lot Five (5), in Sycamore Hills, a subdivision in Sections Twenty-two (22) and Twenty-seven (27), Township Fifty-seven (57), Range Thirty (30); in Cameron, Clinton County, Missouri; subject to existing public highways, roads and streets, easements and restrictions of record, if any;

to satisfy said debt and costs.
DAY MILLER, TRUSTEE
Robison & Miller, P.C.
113 North Polk Street
PO Box 499
Maysville, MO 64469
Telephone: (816) 449-2132
2/20, 27, 3/5, 12c

In Re: Linda Lee, a single person

TRUSTEE’S SALE – Under the terms of the Deed of Trust executed by Linda Lee, a single person dated 07/03/2014, and recorded on 07/07/2014 Document 2014-1763 in the office of the Recorder of Deeds for Clinton County, MISSOURI, the undersigned Successor Trustee, will on 03/13/2020 at 3:00 PM at the West Front Door of the Clinton County Courthouse, 207 N. Main St. Plattsburg MO 64477, sell at public venue to the highest bidder for cash subject to the terms announced at the sale, the realty described in said deed of trust, to wit:

ALL OF LOT 4 IN BLOCK 96 IN HUNT AND GODFREY`S ADDITION TO THE CITY OF CAMERON, CLINTON COUNTY, MISSOURI..

Substitute Trustee Corporation
SUCCESSOR TRUSTEE
HYPERLINK “http://www.substitutetrusteecorp.com/”www.substitutetrusteecorp.com

Published in the Clinton County Leader
File #: LEELICHL
First publication date 02/20/2020
*__12478398__*
2/20, 27, 3/5, 12c

legals

Author

Archives

Categories